Oil & Gas Clean-Up Not "Capped"

On June 27, 2025, in an Opinion authored by Justice Amy Coney Barrett, the United States Supreme Court determined that “universal injunctions,” injunctions issued by district judges that apply nationwide, “likely exceed the equitable authority that Congress has given to federal courts.” In Trump v. CASA, Inc., the Supreme Court, with a 6-3 vote, concluded that district courts do not have authority to issue universal injunctions which seek to prohibit the enforcement of a law or policy against anyone nationwide. The decision limits the relief afforded by the district courts in consolidated matters to only the parties in those actions.

By prohibiting the use of “universal injunctions” in federal courts, litigants already have started to utilize another procedure to seek the relief they seek – class actions. Class actions are a special procedure provided by both federal and state law that allows one or more class representatives to file suit and seek to represent the interests of other similarly situated individuals or companies. Prior to the Supreme Court’s ruling in Trump v. CASA, Inc., a single litigant could apply for a universal injunction through an individual action. Now that the Supreme Court has declared that process unavailable for application of an injunction nationwide, class actions may be the procedural process litigants attempt to use to achieve that same purpose. It remains to be seen whether class actions will be an effective way to achieve broader relief for individuals impacted by government policies.

References:

Trump v. CASA, Inc., --- S.Ct. ---, No. 24A884, 2025 WL 1773631 (U.S. June 27, 2025).

The Louisiana Supreme Court recently held that failure to pay filing fees necessary to add a defendant does not invalidate the proceeding as to other defendants. Prior to the ruling, Louisiana courts held that a failure to pay for one defendant invalidated the entire proceeding.

In Kirt v. Metzinger 2019-C-1162 (La. 04/03/20), plaintiffs requested a medical review panel after the death of their mother due to complications after surgery. Plaintiffs named three defendants—two doctors and the hospital. A letter from the Patient’s Compensation Fund Oversight Board (PCF) was mailed to the plaintiffs, confirming that the defendants were qualified under the Louisiana Medical Malpractice Act, and informing the plaintiffs that they were required by La. R.S. 40:1231.8 to pay a filing fee of $100 per named defendant within forty-five days of the mailing of the letter. Plaintiffs responded, requesting to add two additional defendants to the panel, one of whom was an unidentifiable nurse. Plaintiffs also included payment of $500.

The PCF responded that it was unable to add the nurse without proper identification. Three weeks later, plaintiffs notified the PCF they were also unable to identify the nurse. Upon request, Parish Anesthesia was added to the panel instead. Nearly five months later, plaintiffs provided the PCF with the identity of the nurse in question and requested she be added. The PCF sent confirmed the addition and requested another $100 filing fee which was never paid. Nevertheless, the medical review panel thereafter determined that none of the defendants, including the nurse, breached their standard of care. Suit followed against all defendants.

The defendants moved for summary judgment, arguing that the failure to pay the additional filing fee invalidated the proceeding as to all defendants. The trial court granted this motion, and the appellate court affirmed. Reversing the lower courts, the Supreme Court found that the failure to pay the additional $100 filing fee did not invalidate the entire proceeding. The court observed that separate confirmation letters sent by the PCF provided a different forty-five day period during which to pay the filing fee tied to each individual defendant.

The Kirt court stated: “[t]he notion of ‘one filing fee’ for every panel proceeding cannot be reconciled with the different payment deadlines that arise when the PCF sends separate letters confirming defendants’ qualified status. A single filing fee cannot be subject to different payment deadlines.” The court dismissed only the nurse and remanded the remainder of case to the lower courts.

Chad A. Sullivan is a partner with Keogh, Cox & Wilson, Ltd. Prior to becoming an attorney, he worked as a licensed Registered Nurse. He utilizes his background in nursing on a daily basis in his law practice that primarily focuses on automobile liability, medical malpractice, nursing home litigation, healthcare professional licensure and discipline, and products liability.

The Supreme Court ruling in Couvillion Group, LLC v. Plaquemines Parish Government, 2020 -00074 (La. 4/27/20) is a reminder that an indemnity claim must be sufficiently related to the principal demand and that contract indemnity provisions are to be strictly construed.

In Couvillion, the general contractor sued the owner of a public works port project for contract delay damages resulting from a cease work order issued to allow redesign of a fuel tank platform. When the contractor submitted its delay claim, the owner requested that its project engineer review it and make recommendations. The engineer recommended payment of a little over $1 million dollars. When the owner refused to pay, the contractor sued. In response, the owner filed a third-party demand against the engineer alleging that its recommendation was erroneous and excessive and that, if it was bound by the engineer’s recommendation, then the engineer must indemnify the owner.

On behalf of the engineer, Keogh Cox attorneys argued that the engineer should not be required to reimburse the owner for any delay costs and asked for dismissal through an exception of no cause of action. Code of Procedure Article 1111 provides that a defendant in a principal action may bring in any person who may be liable to him for all or part of the principal demand. Here, that was not the situation. The engineer was not liable to the owner for any part of the contractor’s delay claim because the engineer did not cause the delay. The delay damages were incurred before the engineer made a recommendation for payment. The events giving rise to the two claims were separate and distinct: the main demand arose from the project delay and the third- party demand arose from the engineer’s recommendation of the claim amount. The Court commented that the principal claim against the owner for delay damages was too attenuated from the owner’s claim against the engineer, thus the third-party demand was improper.

The owner also relied on the indemnity provision in the engineer’s contract that required the engineer to indemnify the owner against any and all claims for personal injury or “damages to property” that may arise from its services. The Court held that the plain meaning of the term did not include the economic-only losses related to the subject delay claim. The Court further reasoned that indemnity agreements are to be strictly construed, rejecting the owner’s broader interpretation.