Court Awards Realtor Commission and Attorney’s Fees Despite Breach of Purchase Agreement

Louisiana is a river delta state filled with fertile land and the refusal of its local fauna to stay within boundaries is a problem. Trees create hazards. They also bring nuisance in all its forms––pine sap drizzled over a new car, an oak branch casting a sun-blocking shadow over the perfect tanning spot, and on and on. If you own the tree, the problem is easy enough to address; but what if the tree belongs to your neighbor? Can you cut your neighbor’s tree?

While the Louisiana Civil Code provides guidance, it does not answer every question. Under the Civil Code, “a landowner has the right to demand that the branches or roots of a neighbor’s trees, bushes, or plants, that extend over or into his property be trimmed at the expense of the neighbor.” La. Civil Code Art. 688. Nevertheless, the right to "demand" that the problem be addressed is not a “license to cut;” and does not permit a landowner to cut without permission. Kahl v. Luster, 110 So.3d 1101 (La. App. 1 Cir. 12/28/12).In the event a neighbor is less than neighborly and refuses to trim back a trespassing branch, a landowner may bring an "injunction" against his neighbor. Such an action was involved in Scott v. Ramos, 399 So.2d 1266 (La. App. 4 Cir. 1981) where the defendant/neighbor's large oak tree extended over the plaintiff's property and deposited leaves and branches onto his roof and into his yard. In defense of the action, the defendant presented evidence that cutting the tree back to the property line would essentially kill the tree. Over these objections, the Louisiana Fourth Circuit Court of Appeal granted plaintiff a permanent injunction which required the defendant neighbor to “keep the tree, its limbs and branches cut” back to the property line. Further, the court ordered that defendant reimburse the plaintiff for the cost of removing leaves and fallen debris once a year.So, should your neighbor’s tree ever present a hazard or impede on the enjoyment of your property, there are means of relief. However, gassing up your chainsaw, without your neighbor’s permission, is not one of them.

Louisiana’s anti-indemnity statute applicable to construction contracts, R.S. 9:2780.1, became law in 2011. The statute renders unenforceable any provision in, or collateral to, a construction contract that purports to indemnify or hold harmless a person from liability for its own negligence, or has the effect of doing so. Since the law's passage, few court decisions have interpreted its seemingly broad language and many questions remain as to the law's full impact.

The obvious intent of the anti-indemnity law is to avoid shifting liability away from a party at fault to another person. To this end, the language in the statute nullifies any agreement that has "the effect of holding the person at fault harmless.” But what about "limit of liability" provisions? Arguably, such provisions have the effect of holding harmless the party at fault. Does a limit of liability provision, otherwise valid and enforceable under Louisiana law, run afoul of the anti-indemnity statute? After all, those parties with superior bargaining power in construction contracts will seek to insulate themselves from liability to the fullest extent allowed by law, and will look for alternatives to the indemnity provisions that now expressly violate public policy.

One court recently held that R.S. 9:2780.1 does not prohibit a limit of liability provision in a construction contract. In Patriot Contracting, LLC v. Star Insurance Company, (E.D. La. 3/01/2018), the construction contract contained a provision that excluded liability of the architect for good faith decisions made during contract administration. The plaintiff/contractor alleged that the architect was negligent in its contract administration duties and caused it to suffer economic loss. The court dismissed the claim, rejecting the contractor’s argument that the provision violated the anti-indemnity law.

The Patriot court explained that the statute prohibits an indemnity agreement, i.e., where one party agrees to reimburse a second party for damages for which the second party becomes liable to a third party. However, the anti-indemnity law did not impact the provision that excluded the contractor’s right to recover from the architect. Thus, at at least according to one court, parties in construction contracts are still free to include limit of liability provisions.

Mary Anne Wolf is an engineer/attorney with a construction background who represents design professionals, contractors, and others in construction litigation. She also gives seminars on the subject. She enjoys travel, yoga, and encouraging her husband in his gardening and cooking endeavors.

Generally, a provision in a construction contract for private work limiting the contractor's right to recover additional costs arising from delays outside of the contractor's control may be enforceable. However, under the Public Bid Law, such a provision has been found to be against public policy. La. R.S. 38:2216 prohibits any public contract provision that purports to waive, release or extinguish the rights of a contractor to recover delay damages if the delay was caused in whole or in part by the acts or omission of the public entity.

A recent First Circuit decision struck down a contract provision that purported to limit a contractor's right to damages in a public contract. In F.H. Myers Const. Corp. v. State, Div. of Admin. Office of Facility Planning & Control, 2013-2153 (La.App. 1 Cir. 6/18/14), reh'g denied (July 22, 2014), a general contractor brought an action against the State for breach of contract, seeking payments for extended-fixed job site overhead.

The State argued that the contract contemplated that the contractor could recover extended-fixed job site overhead only if there was a complete stoppage of work solely attributable to the State. The contractor argued that the contract provision was in violation of La. R.S. 38:2216.

The court found that La. R.S. 38:2216 contemplates that a contractor who is a party to a public contract shall be able to recover for any delay they may suffer from the fault of the State entity. Because the contract waived the contractor's rights to seek damages for extended-fixed job site overhead for any delay short of a complete stoppage of work, the contract imposed a stricter limit on damages than the statute allows. The court also noted that the contract only allowed for damages where the State was 100% at fault, whereas the statute allows recovery even if the State is only partially at fault. As such, the provisions at issue were held to be void and unenforceable.